February 25, 2017
Facebook Logo graphic
Twitter Logo graphic
google+ Logo graphic
login
NOW: 22°
HI 27 / LO 24

Kenosha News Legal Notices

Keywords


Start Date


End Date



Records found: 19

Published: Feb. 25, 2017,
ADVERTISEMENT FOR BID
NOTICE TO CONTRACTORS

Kenosha Water Utility
4401 Green Bay Road
Kenosha, WI 53144
Sealed proposals will be received by the Board of Water Commissioners of the City of Kenosha, Wisconsin, in the office of the Kenosha Water Utility, 4401 Green Bay Road, until 2:00 p.m., local time, March 15, 2017, for furnishing all labor and materials necessary for the construction of:
Contract 2017-02-W
Water Main Relay – Phase 1
22nd Avenue – 79th Street
to 80th Street
40th Avenue – 45th Street to
52nd Street
(2,586 LF of 12” Water Main and 500 LF of 8” Water Main)

all in accordance with specifications on file in the office of Kenosha Water Utility Engineering Services. Bids will be publicly opened and read aloud immediately after 2:00 p.m.
Each bid must contain the full name of every person or company interested in the same and must be accompanied by a contract and bid bond, a certified check, or a bank cashier’s check, in the sum of five percent (5%) of the bid, payable to the Kenosha Water Utility as a guarantee that if the bid is accepted, a contract will be entered into and its performance properly secured within fifteen (15) days of the award of contract. Should any bid be rejected, such check will be forthwith returned to the bidder, and should any bid be accepted, such check will be returned upon the timely and proper execution and securing of the contract. In case the successful bidder shall fail to execute the contract and performance bond, the amount of the bid bond or check shall be forfeited to the City as liquidated damages.
There are two options to obtain Plans, Specifications and “Proof of Responsibility”:
Option 1
Plans and specifications will be furnished upon application, and a non-refundable fee paid to the Kenosha Water Utility of Twenty Five Dollars ($25.00) each, for up to three (3) sets of plans/specifications. Prospective bidders may obtain bid documents by mail upon payment of an additional Ten Dollars ($10.00) non-refundable fee to cover the mailing cost.
Option 2
The Kenosha Water Utility has begun a partnership with Quest Construction Data Network. This is a web based initiative that will deliver our construction project advertisements and bid documents to you in a more timely and cost effective way. To obtain an electronic delivery of bid documents go to kenosha.org. Under Departments choose Water Utility. On the left menu bar choose Construction Projects & Specifications. A fee of Ten Dollars ($10.00) will be charged for any bid documents you download.
The form provided for "Bidders Proof of Responsibility" shall be completed and returned to the General Manager not less than (5) calendar days before the date of bid opening.
The successful bidder shall be required to furnish Worker’s Compensation and Liability Insurance as enumerated in the specifications.
The Kenosha Water Utility reserves the right to reject any or all bids, or to accept any bid considered most advantageous to the Kenosha Water Utility.
BOARD OF WATER
COMMISSIONERS, KENOSHA,
WISCONSIN

G. John Ruffolo, Chairperson
Kevin E. Mathewson, Vice Chairperson David F. Bogdala
Jesse Downing
John Fox
Mitchell Pedersen
Feb. 24, 2017 and March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
ADVERTISEMENT TO BID
NOTICE TO CONTRACTORS

Kenosha Water Utility
4401 Green Bay Road
Kenosha, WI 53144
Sealed proposals will be received by the Board of Water Commissioners of the City of Kenosha, Wisconsin, in the office of the Kenosha Water Utility, 4401 Green Bay Road, until 2:00 p.m., local time, March 15, 2017, for furnishing all labor and materials necessary for the construction of:
Contract 2017-01-PROD
75th Street Elevated Storage
Tank Painting

all in accordance with specifications on file in the office of Kenosha Water Utility Engineering Services. Bids will be publicly opened and read aloud immediately after 2:00 p.m.
Each bid must contain the full name of every person or company interested in the same and must be accompanied by a contract and bid bond, a certified check, or a bank cashier’s check, in the sum of five percent (5%) of the bid, payable to the Kenosha Water Utility as a guarantee that if the bid is accepted, a contract will be entered into and its performance properly secured within fifteen (15) days of the award of contract. Should any bid be rejected, such check will be forthwith returned to the bidder, and should any bid be accepted, such check will be returned upon the timely and proper execution and securing of the contract. In case the successful bidder shall fail to execute the contract and performance bond, the amount of the bid bond or check shall be forfeited to the City as liquidated damages.
There are two options to obtain Plans, Specifications and “Proof of Responsibility”:
Option 1
Plans and specifications will be furnished upon application, and a non-refundable fee paid to the Kenosha Water Utility of Twenty Five Dollars ($25.00) each, for up to three (3) sets of plans/specifications. Prospective bidders may obtain bid documents by mail upon payment of an additional Ten Dollars ($10.00) non-refundable fee to cover the mailing cost.
Option 2
The Kenosha Water Utility has begun a partnership with Quest Construction Data Network. This is a web based initiative that will deliver our construction project advertisements and bid documents to you in a more timely and cost effective way. To obtain an electronic delivery of bid documents go to kenosha.org. Under Departments choose Water Utility. On the left menu bar choose Construction Projects & Specifications. A fee of Ten Dollars ($10.00) will be charged for any bid documents you download.
The form provided for "Bidders Proof of Responsibility" shall be completed and returned to the General Manager not less than (5) calendar days before the date of bid opening.
The successful bidder shall be required to furnish Worker’s Compensation and Liability Insurance as enumerated in the specifications.
The Kenosha Water Utility reserves the right to reject any or all bids, or to accept any bid considered most advantageous to the Kenosha Water Utility.
BOARD OF WATER
COMMISSIONERS, KENOSHA,
WISCONSIN

G. John Ruffolo, Chairperson
Kevin E. Mathewson, Vice Chairperson David F. Bogdala
Jesse Downing
John Fox
Mitchell Pedersen
Published Feb. 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
WAUKESHA COUNTY
Wisconsin Veterinary Referral Center
VS
Luevette Wise and possible spouse of Luevette Wise
4319 6th Avenue
Kenosha, WI 53140
SMALL CLAIMS
Case No. 2017SC000193
You are being sued by Wisconsin Veterinary Referral Center in the small claims court for Waukesha County, Wisconsin, Room 167 of the Waukesha County Courthouse, 515 W. Moreland Blvd, Waukesha, WI 53188. The hearing will be held on March 20, 2017 at 1:00 PM.
If you do not appear a judgment may be given to the person suing you. (A copy of the claim has been mailed to you at the address above.)
Dated this 21st day of February, 2017
/s/
Joseph L. Cook
State Bar #1013126
Cook Law Office
P.P. Box 1405
Waukesha, WI 53187
262-547-7739
Published: February 24, 2017
WNAXLP



Published: Feb. 25, 2017,
ORD. #17-07
AN ORDINANCE TO AMEND
SUBSECTION 420-131 I OF
THE VILLAGE OF PLEASANT PRAIRIE ZONING ORDINANCE

BE IT ORDAINED AND ESTABLISHED by the Village Board of Trustees of the Village of Pleasant Prairie, Kenosha County, Wisconsin, that Subsection 420-131 I of the Village of Zoning Ordinance, relating to official floodplain maps and studies, is hereby amended to read as follows:
I. Official floodplain maps and studies.
(1) Subject to the provisions of Subsections O, R and S below, the boundaries of the floodplain areas, including both the floodway and the flood-fringe areas, and the boundaries of the floodway areas (all as defined in Subsection CC below), and the water surface elevations of the regional flood profile, are as designated on the official floodplain maps or as stated in or determinable from other official DNR- and FEMA-approved technical studies, listed below, which are hereby adopted and incorporated by reference. These official floodplain maps and studies are on file in the office of the Village of Pleasant Prairie Zoning Administrator. In the event of a conflict between any of the maps or studies referred to in this Subsection I, the most restrictive information shall apply.
(a) Flood Insurance Rate Maps (FIRMs) prepared by FEMA for the Kenosha County and Incorporated Areas, Map Number 55059CIN0A 55059CIND0B, effective date March 7, 2017 June 19, 2012, Panels 55059C0179D, 55059C0183D, 55059C0184D, 55059C0187D, 55059C0188D, 55059C0189D, 55059C0191D, 55059C0192D, 55059C0193D, 55059C0194D, 55059C0203D, 55059C00211D, 55059C00212D, 55059C00213D, 55059C00214D, 55059C00216D, 55059C00218D, 55059C00302D, 55059C00306D, 55059C00307D, 55059C00326D, 55059C00327D and 55059C00331D, and the related Flood Insurance Study for Kenosha County, Wisconsin, and Incorporated Areas, prepared by FEMA, effective June 19, 2012., Flood Insurance Study Number 55059CV001A and 55059CV002A. The following amendments included:
[1] FIRM Map Number 55059C0189D Amended pursuant to FEMA LOMA LOMR Case 16-05-7542P dated November 2, 2016 and effective March 23, 2017.
[2] FIRM Map Numbers 55059C0184E and 55059C0192E as amended with a Map Revision date of March 7, 2017.
[3] Flood Insurance Study for Kenosha County, Wisconsin, and Incorporated Areas, prepared by FEMA, with an effective date of March 7, 2017 Flood Insurance Study Numbers 55059CV001B 55059CV002B.
(b) Map A-2 titled "Floodplains in the Chiwaukee Prairie - Carol Beach Study Area Under Existing and Future Development Conditions" and Table A-3 titled "100-Year Recurrence Interval Flood Stages for the Chiwaukee Prairie - Carol Beach Study Area Under Existing and Future Development Conditions," pages 189 and 188, respectively, of SEWRPC Community Assistance Planning Report No. 88, titled "A Land Use Management Plan for the Chiwaukee Prairie - Carol Beach Area of the Town of Pleasant Prairie, Kenosha County, Wisconsin," prepared by the Southeastern Regional Planning Commission, February 1985.
Adopted this 20th day of February, 2017.
VILLAGE OF PLEASANT PRAIRIE
/s/
John P. Steinbrink,
Village President
/s/
Jane M. Romanowski
Village Clerk
Published: February 24, 2017
WNAXLP

Published: Feb. 25, 2017,
NOTICE of PUBLIC HEARING
VILLAGE of SOMERS
BOARD of APPEALS

Please take notice that the Village of Somers Board of Appeals will meet on March 1, 2017 at 5:30 p.m. at the Somers Village Hall, 7511 12th Street, Somers, WI to hold a public hearing on the following request:
Todd & Kristin Armstrong, 454 47th Ave., Kenosha, WI 53144-1022 (Owner), requesting a variance (Section V. 12.27-6(d): which states that all detached accessory structures shall be located in the side or rear yard only and that there shall be a maximum of two detached accessory buildings of which one accessory building shall be limited to a maximum of 1,500 square feet in area and a second accessory building shall be limited to a maximum of 150 square feet in area for the two buildings not to exceed a total of 1,650 square feet; and Section IV. C 12.21-2(g)1: which states that all structures shall be located not less than thirty (30) feet from the right-of-way of all other roads in the R-2 Urban Single-Family Residential Dist.) to construct in the street yard (side or rear yard required) a 30’ x 50’ accessory building (1500 sq. ft.) to be located 20.21’ from the right-of-way of 47th Ave. (30’ required), and to allow two existing accessory buildings larger than 150 sq. ft. to remain for a total combined detached accessory building area of 2,069.85 sq. ft. (1,650 sq. ft. required), on Tax Parcel #82-4-222-023-0046, Village of Somers.
Village of Somers
Timothy L. Kitzman, Village Clerk-Treasurer
Published: February 24, 28, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
MGM HEALTHCARE
d/b/a
SHERIDAN
MEDICAL COMPLEX
Plaintiff
v.
WILLIAM L. TOMCZAK
Defendant.
Case No. 17 CV 150
Case Code: 30301
The Honorable Chad G. Kerkman
SUMMONS BY PUBLICATION
THE STATE OF WISCONSIN, to each person named above as Defendant:
You are hereby notified that the Plaintiff named above has filed a lawsuit or other legal action against you.
Within 20 days after February 26, 2017, you must respond with a written demand for a copy of the complaint. The demand must be sent or delivered to the court, whose address is 912 - 56th Street, Kenosha, WI 53140. You may have an attorney help or represent you.
If you do not demand a copy of the complaint within 20 days, the court may grant judgment against you for the award of money or other legal action requested in the complaint. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property.
Dated at Kenosha, Wisconsin this 20th day of February, 2016.
By: Erik H. Guttormsen,
Attorney for Plaintiff
State Bar No. 1041446
GUTTORMSEN & HARTLEY, LLP
600 - 52nd Street, Suite 200
Kenosha, WI 53140
Phone: 262-658-4800
Fax 262-658-0102
Published Feb. 24, March 3, 10, 2017
WNAXLP




Published: Feb. 25, 2017,
NOTICE TO CONSTRUCT OR REPlace PUBLIC SIDEWALK AND/OR DRIVEWAY APPROACH
PROJECT NO. 17-1016
22nd AVENUE RESURFACING
(22nd AVENUE – 75th STREET TO 80th STREET)
Project No. 17-1016
Date: February 20, 2017

The City of Kenosha, Department of Public Works, has determined the need to construct or replace public sidewalk and/or driveway approach abutting parcels of property as shown on a list on file in the office of the Department of Public Works. Such parcels lie along the above referenced street(s) that are being recommended for resurfacing to the Common Council.
Should the Common Council approve the recommended sidewalk and/or driveway approach work, following a Public Hearing, you will be mailed a copy of the Resolution directing such Work.
A property owner may choose to have the sidewalk and/or driveway approach Work done on their own upon obtaining a proper permit in accordance with provisions of Chapter 5 of the Code of General Ordinances. The property owner must state his/her intentions of doing the Work on their own to the project engineer in a timely manner, and may do so by applying for the permit to do the Work prior to MAY 26, 2017. If the project engineer does not hear from the property owner, or a permit is not taken out by the property owner at the time the Citys contractor is working on the block, the City will go ahead and have its contractor proceed with the removal/replacement as shown on the list. Likewise, if the property owner choosing to do the work themselves does not, the Common Council shall cause the Work to be done at your expense by contract let to the lowest responsible bidder, and the Work will be paid for by assessing the cost of the Work to your property. Invoices for said Work will be sent out the year following construction. If the cost of Work is under One Hundred ($100.00) Dollars, it shall be paid in its entirety within thirty (30) days of receipt of invoice. If the cost of Work is over One Hundred ($100.00) Dollars, it may be paid in its entirety within thirty (30) days of receipt of invoice, and if not so paid, placed on the tax roll for a period of three (3) years at an interest rate of seven and one-half (7.5%) per annum. If not paid within the period fixed, such a delinquent special charge shall become a lien as provided in Section 66.0715(3), Wisconsin Statutes, as of the date of such delinquency, and shall automatically be extended upon the current or next tax roll as a delinquent tax against the property and all proceedings in relation to the collection, return and sale of property for delinquent real estate taxes shall apply to such special charge.
A Public Hearing will be held before the Public Works Committee at 5:30 PM, on Monday, March 27, 2017, in Room 202, and before the Common Council at 7:00 PM on Monday, April 3, 2017, in Room 200 of the Municipal Building, located at 625 – 52nd Street, Kenosha, Wisconsin.
If you have any questions regarding this Notice or the Work, please contact Project Engineer, Ben Schultz at (262)653-4151. YOU ARE NOT REQUIRED TO ATTEND THE PUBLIC HEARING UNLESS YOU DISPUTE THE PROPOSED SIDEWALK AND/OR DRIVEWAY APPROACH CONSTRUCTION OR REPlaceMENT.
/s/
CATHY AUSTIN, PE
Deputy Director of Public Works/City Engineer
Published: February 24, 2017
WNAXLP

Published: Feb. 25, 2017,
Village of Bristol
Bid Notice For Street Trees on
194th Avenue South of 84th
Street to 87th street.

Notice is hereby given; that sealed bids will be received in envelopes marked “SEALED BID STTREET TREES” by the Village of Bristol at the Bristol Village Hall, 19801 83rd Street, Bristol, Wisconsin, until 10:15 AM March 10, 2017 for furnishing all labor and materials necessary for the construction and laying of the following work.
The contractor plant 19 trees per the specifications at the Village Hall. All plant material shall conform to American Standards for Nursery Stock (ANSI Z60.1).
The Village Board reserves the right to reject any and all bids and solicit for new bids and/or waive any informalities in the proposals and to accept or reject all alternatives or unit prices if, in its opinion, the best interest of the Village will be promoted.
Proposal shall be accompanied by a Certified Check or Bid Bond in the amount of 10 percent of the maximum bid, payable to the Village of Bristol as a guarantee that the bidder, if the bid is accepted, will execute and file the Contract. The Certified Check is returnable to the bidder immediately after the signing of the Contract.
All work under this contract shall be completed by June 15, 2017.
Specifications and bid forms may be obtained in the Village office for the above-mentioned work.
Bids will be opened at 10:15 AM, March 10, 2017 At the Village Hall Meeting Room.
Published: February 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
VILLAGE OF BRISTOL
BID NOTICE FOR LAWN MOWING OF VILLAGE PROPERTY

Notice is hereby given, that sealed bids will be received in envelopes marked "SEALED BID LAWN MOWING" by the Village of Bristol at the Bristol Village Hall, 19801 83rd Street, Bristol, Wisconsin until 10:30 AM on March 10, 2017 for furnishing all labor and materials necessary for the maintenance of grass for the following work.
The mowing area shall be the same as last year. Mowing will be done per the specifications within the proposal.
Bidders must be present at the Village Board meeting for award to answer any questions.
The Village Board reserves the right to reject any and all bids and solicit for new bids and/or waive any informalities in the proposals and to accept or reject all alternatives or unit prices if, in its opinion, the best interest of the Village will be promoted.
Specifications and bid forms may be obtained in the Village Office for the above mentioned work.
Bids will be opened at 10:30 a.m. March 10, 2017 at the Village Meeting Room.
Published: February 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
Village of Bristol
Bid Notice For Paving Projects

Notice is hereby given, that sealed bids will be received in envelopes marked “SEALED BID PAVING” by the Village of Bristol at the Bristol Village Hall, 19801 83RD Street, Bristol, Wisconsin, until 10:00 AM March 10, 2017 for furnishing all labor and materials necessary for the construction and laying of the following work.
Laying of approximately 1.32 miles of bituminous asphalt and approximately 1.32 miles of pavement pulverization on village roads. All work will be done in accordance with Wisconsin State Statutes and State of Wisconsin Department of Transportation Standard Specification for Road Construction 2010 Edition.
The Village Board reserves the right to reject any and all bids and solicit for new bids and/or waive any informalities in the proposals and to accept or reject all alternatives or unit prices if, in its opinion, the best interest of the Village will be promoted.
Proposal shall be accompanied by a Certified Check or Bid Bond in the amount of 10 percent of the maximum bid, payable to the Village of Bristol as a guarantee that the bidder, if the bid is accepted, will execute and file the Contract. The Certified Check is returnable to the bidder immediately after the signing of the Contract.
A Performance bond and payment bond in the amount of 120 percent of the total bid price, a Certificate of Insurance, together with an executed contract, will be required of the successful bidder.
All work under this contract shall be completed by September 15, 2017.
Specifications and bid forms may be obtained in the Village office for the above-mentioned work.
Bids will be opened at 10:00 March 10, 2017 At the Village Hall Meeting Room.
Published: February 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
NOTICE
The Board of Canvassers of Joint School District #1, Silver Lake - Salem will be meeting at 3:45 PM on February 27, 2017 in the Main Office/Conference Room at Riverview School.
The purpose is to review the returns of the Spring Primary Election conducted on February 21, 2017, certify the results and determine the candidates elected to be placed on the ballot for the Spring Election for the two positions up for election for the school board of Joint School District #1, Silver Lake-Salem.
Published: February 24, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
CREDIT ACCEPTANCE
CORPORATION
Plaintiff,
vs.
RAPHAEL FIGUEROA III
Defendant.
PUBLICATION SUMMONS
Case No.: 16-CV-1408
STATE OF WISCONSIN:
To each person named above as a Defendant:
You are hereby notified that the Plaintiff named above has filed a lawsuit or other legal action against you.
Within 40 days after February 24, 2017, you must respond with a written demand for a copy of the Complaint. The demand must be sent or delivered to the Court, whose address is Clerk of Court, Kenosha County Courthouse, 912 56th Street, Kenosha, WI 53140 and to Plaintiff’s attorney, whose address is One Corporate Drive, Suite 400, P.O. Box 1519, Wausau, Wisconsin 54402-1519. You may have an attorney help or represent you.
If you do not demand a copy of the Complaint within 40 days, the court may grant judgment against you for the award of money or other legal action requested in the Complaint, and you may lose your right to object to anything that is or may be incorrect in the Complaint. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property.
Dated: February 16, 2017
/s/
Michael A. Stueland
Attorney for Plaintiff
State Bar No. 1066376
Daubert Law Firm, LLC
One Corporate Drive, Suite 400
P.O. Box 1519
Wausau, WI 54402-1519
(715) 845-1805
Published: February 24, March 3, 10, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
IN THE MATTER OF THE ESTATE OF
Terri Ann Shinske
ORDER SETTING Time TO HEAR PETITION FOR ADMINISTRATION AND DEADLINE FOR FILING CLAIMS
Case No. 17PR16
A petition for informal administration was filed.
THE COURT FINDS:
The decedent, with date of birth 03/08/46 and date of death 01/01/17 was domiciled in Kenosha County, State of Wisconsin, with a mailing address of 3105 85th Street, Apt. 9, Kenosha, WI 53132.
THE COURT ORDERS:
1. The petition be heard at the Kenosha County Courthouse, 912 56th Street, Kenosha, Wisconsin, Room 228, before Circuit Court Judge/Circuit Court Commissioner Chad G. Kerkman, on 3/23/2017 at 10:45 AM.
2. The deadline for filing a claim against the decedent’s estate is June 6, 2017.
3. A claim may be filed at the Kenosha County Courthouse, 912 56th Street, Kenosha, Wisconsin, Room LL4.
4. Heirship will be determined at the hearing on petition for final judgment.
5. Publication of this notice to any persons whose names or addresses are unknown.
Dated: February 6, 2017
/s/
Chad G. Kerkman
Circuit Judge Branch 8
Michael M. Easton
Law Offices of Michael M. Easton, LLC
7500 Green Bay Road, Ste 201
Kenosha, WI 53142
262-654-8669
Bar Number 1038423
Published: February 17, 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
IN THE MATTER OF THE ESTATE OF
Gerald E. Kaiser
ORDER SETTING Time TO HEAR PETITION FOR ADMINISTRATION AND DEADLINE FOR FILING CLAIMS
Case No. 17PR24
A petition for informal administration was filed.
THE COURT FINDS:
The decedent, with date of birth 08/25/1939 and date of death 01/19/2017 was domiciled in Kenosha County, State of Wisconsin, with a mailing address of 2603 22nd Avenue, Kenosha, WI 53140.
THE COURT ORDERS:
1. The petition be heard at the Kenosha County Courthouse, Kenosha, Wisconsin, Room 117, before Circuit Court Judge Anthony Milisauskas, on March 15, 2017 at 9:00 AM.
2. The deadline for filing a claim against the decedent’s estate is June 8, 2017.
3. A claim may be filed at the Kenosha County Courthouse, Kenosha, Wisconsin, Room LL4.
4. Heirship will be determined at the hearing on petition for final judgment.
5. Publication of this notice is notice to any persons whose names or addresses are unknown.
Dated: February 8, 2017
/s/
Anthony Milisauskas
Circuit Judge Branch 4
Nathaniel S. Lepp
Nathaniel S. Lepp, S.C.
624 57th Street
Kenosha, WI 53140
262-658-8128
Bar Number 1008581
Published: February 17, 24, March 3, 2017
WNAXLP


Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
UNIVERSITY OF WISCONSIN
MILWAUKEE
Plaintiff,
vs.
CHRISOPHER A ROUSHIA
Defendant.
AMENDED SUMMONS
Case No. 16CV001463
THE STATE OF WISCONSIN
TO: CHRISOPHER A ROUSHIA 5305 52ND ST #22 KENOSHA WI 53142
You are hereby notified that the Plaintiff named above has filed a lawsuit or other legal action against you. The Complaint, which is also served on you, states the nature and basis of the legal action.
Within Forty (40) days after February 17, 2017, you must respond with a written answer, as that term is used in Chapter 802 of the Wisconsin Statutes, to the Complaint. The court may reject or disregard an answer that does not follow the requirements of the statutes. The answer must be sent or delivered to the court, whose address is: CLERK OF CIRCUIT COURT, KENOSHA COUNTY, 912 56TH STREET, KENOSHA WI 53140 and the Kohn Law Firm, Plaintiffs attorneys, whose address is 735 N. Water St., Suite 1300, Milwaukee, WI 53202. You may have an attorney help or represent you.
If no Complaint accompanies this Summons you must respond within the said 40 day period with a written demand for a copy of the Complaint by mailing or delivering said written demand to the court and to the Plaintiffs attorneys at their respective addresses listed above.
If you do not provide a proper answer to the Complaint or provide a written demand for said complaint within the 40 day period, the court may grant judgment against you for the award of money or other legal action requested in the Complaint, and you may lose your right to object to anything that is or may be incorrect in the Complaint. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may be enforced by garnishment or seizure of property.
Dated at Milwaukee, Wisconsin Jan 30 2017.
KOHN LAW FIRM S.C.
/s/
JOSEPH R. JOHNSON
State Bar No. 1053052
Attorney for Plaintiff
Published: February 17, 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
Pacific Union Financial, LLC
1603 LBJ Freeway Suite 500, Mail Stop 60100
Farmers Branch, TX 75234
Plaintiff,
vs.
Julius L. Hibbler a/k/a Julius LaCarl Hibbler
4833 42nd Ave
Kenosha, WI 53144-3551
Kisha N. Hibbler
4833 42nd Ave
Kenosha, WI 53144-3551
Whitecaps Property Owners Association, Inc.
c/o Erik H. Guttorsmen, Registered Agent
600 52nd St Ste 200
Kenosha, WI 53140-3423
Defendants.
PUBLICATION SUMMONS
Case No. 16-CV-1494
Branch 8
The Honorable Chad G. Kerkman Case Code 30404 (Foreclosure of Mortgage) The amount claimed exceeds $10,000.00
THE STATE OF WISCONSIN
To each person named above as a defendant:
You are hereby notified that the plaintiff named above has filed a lawsuit or other legal action against you.
Within 40 days after February 17, 2017 you must respond with a written demand for a copy of the complaint. The demand must be sent or delivered to the court, whose address is 912 56th Street, Kenosha, WI 53140-3736 and to Gray & Associates, L.L.P., plaintiffs attorney, whose address is 16345 West Glendale Drive, New Berlin, WI 53151-2841. You may have an attorney help or represent you.
If you do not demand a copy of the complaint within 40 days, the court may grant judgment against you for the award of money or other legal action requested in the complaint, and you may lose your right to object to anything that is or may be incorrect in the complaint. A judgment may be enforced as provided by law.
A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property.
Dated this 8th day of February, 2017.
Gray & Associates, L.L.P.
Attorneys for Plaintiff
/s/
Ian J. Thomson
State Bar No. 1076280
16345 West Glendale Drive
New Berlin, WI 53151-2841
(414) 224-1987
Gray & Associates, L.L.P. is attempting to collect a debt and any information obtained will be used for that purpose. If you have previously received a discharge in a chapter 7 bankruptcy case, this communication should not be construed as an attempt to hold you personally liable for the debt.
Published: February 17, 24, March 3, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
IN THE MATTER OF TH ESTATE OF
MARY L. WALLACE
NOTICE TO CREDITORS
(Informal Administration)
Case No. 17- PR -23
PLEASE TAKE NOTICE:
1. An application for informal administration was filed.
2. The decedent, with date of birth September 1, 1951 and date of death January 2, 2017, was domiciled in Kenosha County, State of Wisconsin, with a mailing address of 2107 74th Street, Kenosha, WI 53143.
3. All interested persons waived notice.
4. The deadline for filing claim against the decedent’s estate is June 2, 2017.
5. A claim may be filed at the Kenosha County Courthouse, 912 -56th Street, Wisconsin Room LL4.
Kelly A. Bilotti
Probate Registrar
11-30-16
GUTTORMSEN & HARTLEY, LLP
600 - 52ND STREET, SUITE 200
KENOSHA, WI 53140
Phone: 262-658-4800
Bar Number 1041446
Published Feb. 10, 27, 24, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
IN THE MATTER OF THE ESTATE OF
IRENE M. DELLINGER
DECEASED
NOTICE TO CREDITORS
(Informal Administration)
Case NO.17-PR-19
PLEASE TAKE NOTICE:
1. An application for informal administration was filed.
2. The decedent, with date of birth August 10, 1927 and date of death January 24, 2017 was domiciled in Kenosha County, State of Wisconsin with a mailing address of 3119 26th Avenue, Kenosha, WI, 53140.
3. All interested persons waived notice.
4. The deadline for filing a claim against the decedent’s estate is June 3, 2017.
5. A claim may be filed at the KENOSHA County Courthouse, 912 - 56th Street Kenosha, Room LL4.
/s/ Kelly A. Bilotti
Probate Registrar
February 3, 2017
Wokwicz Law Offices, LLC
Attorney Paul B. Wokwicz
6121 Green Bay Rd., STE 240
Kenosha, WI 53142
262-658-2181
Bar Number 1022393
Published Feb. 10, 17, 24, 2017
WNAXLP

Published: Feb. 25, 2017,
STATE OF WISCONSIN
CIRCUIT COURT
KENOSHA COUNTY
TALMER BANKAND TRUST,
Honorable David Bastianelli
Plaintiff,
-vs-
Terry L. Sommer, et al
Defendants.
NOTICE OF FORECLOSURE SALE
Case No. 15 CV 1519
PLEASE TAKE NOTICE that by virtue of an Order for Judgment and Judgment entered June 15, 2016, in favor of Talmer Bank & Trust, in the amount of $140,006.19, the Sheriff will sell the described premises at public auction as follows:
DATE and Time: Wednesday, March 15, 2017 at 10:00 a.m.
Terms OF SALE: Pursuant to said judgment, 10% of the successful bid must be paid to the Sheriff at the sale in cash, cashier’s check or certified funds, payable to the Clerk of Courts (personal checks cannot and will not be accepted). The balance of the successful bid must be paid to the Clerk of Courts in cash, cashier’s check or certified funds no later than 10 days after the Court’s confirmation of the sale or else the 10% down payment is forfeited to the plaintiff. The property is sold “as is” and subject to all liens and encumbrances.
Place: In the Main Lobby, Kenosha County Public Safety Building
1000 55th Street
Kenosha, WI 53140
LEGAL Description OF PROPERTY, ADDRESS, & TAX PARCEL NUMBER:
Legal Description:
Unit 2, together with said units undivided percentage interest in the common elements (and the exclusive use of the limited common elements appurtenant to said unit) all in Gatewood II Condominium, a condominium declared and existing under and by virtue of the Condominium Ownership Act of the State of Wisconsin and recorded by a Declaration as such condominium in the Office of the Register of Deeds for Kenosha County, Wisconsin, on November 24, 2004, as Document No. 1413382, and any further amendments thereto, said condominium being located in the Village of Twin Lakes, County of Kenosha, State of Wisconsin on the real estate described in said Declaration and incorporated herein by this reference thereto.
Tax Key No.: 85-4-119-222-3127
Property Address: 611 GATEWOOD DR
Dated this day of February, 2017.
David G. Beth, Sheriff
Kenosha County, WI
THIS DOCUMENT DRAFTED BY:
Attorney Shannon Wynn
Wynn at Law, LLC
415 Broad St. Suite 2
Lake Geneva, WI 53147
(262) 725-0175
Wynn at Law, LLC is the creditor’s attorney and is attempting to collect a debt on its behalf. Any information obtained will be used for that purpose. If Debtors have filed Bankruptcy, this is not an attempt to collect a debt, but is given for information purposes only.
Published: February 10, 17, 24, 2017
WNAXLP

Content

News
Sports
Life
Obits
Community
Marketplace
Jobs
ePaper
Connect

Customers
Advertisers
Online Forms
Contact Us
Staff
Collaborate

Submit a story or photo
Submit a press release
Submit an entertainment event
Submit Feedback



c: